These Terms and Conditions govern your use of fintech-devs.com and any services provided through the website. By accessing the website or engaging our services, you agree to be bound by these Terms.
Definitions
For the purposes of these Terms:
- Agreement – The contract, proposal, these Terms and Conditions, and any related documentation governing the engagement.
- Client Content – Any materials, data, or information provided by the client.
- Deliverables – The work outputs or results specified in the Agreement.
- Company Tools – Software, systems, templates, frameworks, and proprietary methodologies owned or licensed by fintech-devs.com.
- Final Deliverables – Completed outputs delivered after fulfillment of agreed Services.
- Project – The defined scope of work outlined in the Agreement.
- Services – The professional and technical services provided by fintech-devs.com.
- Third-Party Materials – External tools, software, or content incorporated into the Deliverables where applicable.
Service Delivery
Services are provided in accordance with the scope, milestones, and timelines defined in the Agreement. We apply professional judgment and commercially reasonable efforts in delivering the Services.
Project completion may depend on timely input, approvals, and cooperation from the client.
Proposals and Scope of Work
Service proposals remain valid for thirty (30) days unless otherwise specified. If not accepted within that period, we may revise the proposal before resubmitting.
The scope of Services is limited to what is expressly stated in the Agreement. Any additional work requires written approval.
Fees, Expenses, and Taxes
Unless otherwise specified:
- Third-party services or tools are billed separately
- Approved expenses may be invoiced at cost
- The client is responsible for applicable taxes associated with the Services
Payment Terms
Invoices are due within five (5) days from the invoice date unless otherwise agreed in writing. Payments may follow milestone-based schedules defined in the Agreement.
Changes to Scope
Requests for changes must be submitted in writing.
Minor adjustments that do not materially affect pricing or deadlines may be implemented without formal amendment. Significant changes affecting scope, cost, or timelines require a revised or supplemental Agreement.
Revised proposals should be accepted within fourteen (14) working days unless otherwise agreed.
Delays and Timeline Adjustments
If delays result from the client’s failure to provide required materials, approvals, or feedback, project timelines may be extended accordingly.
If delays occur due to circumstances beyond reasonable control, including force majeure events, such delays will not constitute breach and timelines may be adjusted.
Review and Acceptance
Deliverables are reviewed internally prior to submission.
The client has seven (7) working days to review and provide feedback. Revisions within scope will be completed within a reasonable timeframe.
If no feedback is received during the review period, Deliverables may be considered accepted.
Client Responsibilities
The client agrees to:
- Provide accurate and lawful information
- Ensure Client Content does not infringe third-party rights
- Provide timely approvals and decisions
- Review Deliverables for accuracy unless otherwise agreed
Attribution and Portfolio Use
Unless otherwise agreed, fintech-devs.com may reference completed work in its portfolio or service materials. Such references will remain factual and reasonable.
Confidential Information
Both parties agree to maintain the confidentiality of non-public information shared during the engagement.
This does not apply to information that is publicly available, independently obtained, or required to be disclosed by law.
Independent Contractor Status
fintech-devs.com operates as an independent contractor. Nothing in these Terms creates a partnership, employment relationship, or joint venture.
We may engage subcontractors where appropriate while remaining responsible for service delivery.
Limitation of Liability
To the extent permitted by applicable law, Services are provided on an “as-is” basis. Our total liability for any claim related to the Services shall not exceed the amount paid for the specific Services giving rise to the claim.
Rights to Deliverables
Upon full payment, the client receives a non-exclusive, perpetual, worldwide license to use the Final Deliverables as agreed.
All Company Tools, frameworks, and internal methodologies remain the property of fintech-devs.com unless otherwise agreed in writing.
Support and Maintenance
Support services are provided only if agreed separately. Additional support may be billed separately. Any warranty may be void if Deliverables are modified by unauthorized parties.
Updates to These Terms
We reserve the right to modify these Terms at any time. The version published on fintech-devs.com at the time of use applies. Continued use of the website or Services constitutes acceptance of any updates.